v2181-277

No. 9113

INTHE

United States Circuit Court of Appeals

For the Ninth Circuit

Six Companies of California, a corporation, and

Hartford Accident and Indemnity Company, a

corporation, Fidelity and Deposit Company of

Maryland, a corporation. The Aetna Casualty

AND Surety Company, a corporation, Indemnity

Insurance Company of North America, a corpo-

ration, American Surety Company of New York,

a corporation, Maryland Casualty Company, a

corporation, United States Fidelity and Guar-

anty Company, a corporation. The Fidelity and

Casualty Company of New York, a corporation.

Glens Falls Indemnity Company, a corporation.

Standard Surety and Casualty Company of New

York, a corporation, Standard Accident Insur-

ance Company, a corporation, Massachusetts

Bonding and Insurance Company, a corporation.

Continental Casualty Company, a corporation,

and New Amsterdam Casualty Company, a cor-

poration,

Appellants,

vs.

Joint Highway District No. 13 of the State op

California, a public corporation.

Appellee.

r

APPELLEE'S REPLY TO

BRIEF FOR APPELLANT SURETY COMPANIES.

939

CLEWHt

Archibald B. Tinning,

924 Main Street, Martinez, California,

1. 1. WlTTSOHEN,

Latham Square Building, Oakland, California,

Attorneys for Appellee,

Joint Highway District No. 13

of the State of California.

---

archive.org Volume Name: govuscourtsca9briefs2181

Volume: http://archive.org/stream/govuscourtsca9briefs2181

Document Link: http://archive.org/stream/govuscourtsca9briefs2181#page/n276/mode/1up

Top Keywords (auto-generated):

contractor, district, contract, work, cal, pac, tunnel, damages, california, engineer, specifications, tunnels, delay, 1935, surety

Top Key Phrases (auto-generated):

liquidated damages, district engineer, joint highway, highway district, los angeles, geological report, contract price, answering contractor, san francisco, concrete lining, public works, boggs district, district engineer., underground conditions, ground conditions

Document Status: UGLY