v3356-957

No. 20128

In the

United States Court of Appeals

for the Ninth Circuit

David S. McDaniel, doing business as Mc-

Daniel Plumbing & Heating Company,

Appellant,

vs.

Ashton-Mardian Company (Joint Ven-

ture), and Travelers Indemnity Com-

pany, a corporation,

Appellees.

Appellees' Brief

Hall, Jones, Hannah & Trachta ^^ii

By Ben C. Birdsall -*

By EussELL E. Jones

1010 Valley National Building

Tucson, Arizona

Attorneys for Appellees

^^9ss

50RG PRINTING COMPANY OF CALIFORNIA, 346 FIRST STREET, SAN FRANCISCO 94105

---

archive.org Volume Name: govuscourtsca9briefs3356

Volume: http://archive.org/stream/govuscourtsca9briefs3356

Document Link: http://archive.org/stream/govuscourtsca9briefs3356#page/n956/mode/1up

Top Keywords (auto-generated):

contract, delay, contractor, work, changes, 2d, argument, provisions, government, damages, subcontractor, sub, subcontract, ed, decision

Top Key Phrases (auto-generated):

sub contractor, gen eral, delay damages, ashton mardian, vernon contracting, river dam, mount vernon, grand river, contract provisions, contracting corp., brooker engineering, wells bros., ven ture, trunk western, travelers indemnity

Document Status: UGLY