v3369-785

Document Title Page

^

nJ)^ No. 20@X:

IN THE

United Stales Court of Appeals

For the Ninth Circuit

Baker & Ford Co., a corporation, and

The Fidelity and Casualty Company of New York

a corporation,

Appellants,

United States of America

for the use and benefit of

Urban Plumbing & Heating Co.,

a corporation,

Appellee.

Upon Appeal from the United States District Court

FOR Alaska

Honorable Raymond E. Plummer, Judge

BRIEF OF APPELLANTS

Mike Stepovich

Attorney at Law

Fairbanks, Alaska

p I L 1^ ^UCE T. Rinker

Attorney at Law

r^ o .nc- 317 Bellingham Nat'l Bank Bldg.

JAM 2 19ba BeUingham, Wash.

Attorneys for Appellants

WM, B. LUCiv. CLERK

METROPOLITAN PRESS a^^^o SEATTLE, WASHINGTON


archive.org Volume Name: govuscourtsca9briefs3369

Volume: http://archive.org/stream/govuscourtsca9briefs3369

Document Link: http://archive.org/stream/govuscourtsca9briefs3369#page/n784/mode/1up

Top Keywords (auto-generated):

work, schedule, urban, contract, finding, 1960, completion, extra, additional, brewer, subcontract, dates, costs, baker, errors

Top Key Phrases (auto-generated):

extra work, baker ford, completion dates, prime contractor, finding xvi, contract 1302, personal knowledge, construction schedule, november 20th, finding vii, contract 1282, ap pellee, 536 540, water main, testi mony

Document Status: UGLY