v3369-871

Document Title Page

No. 20381

IN THE

United States Court of Appeals

For the Ninth Circuit

Baker & Ford Co., a corporation, and

The Fidelity and Casualty Company of New York

a corporation,

Appellants,

United States of America

for the use and benefit of

Urban Plumbing & Heating Co.,

a corporation.

Appellee.

Upon Appeal from the United States District Court

FOR Alaska

Honorable Raymond E. Plummer, Judge

BRIEF OF APPELLEE

Fll .-:

Donald McL. Davidson

^i-* ii LJ William B. Moore

fUR 2 Q juffi Attorneys at Law

^ y i.bb 929 Logan Building

Vivi b. LuiK r Seattle, Washington 98101

LhRK Attorneys for Appellee

METROPOLITAN PRESS C0^^o SEATTLE. WASHINGTON


archive.org Volume Name: govuscourtsca9briefs3369

Volume: http://archive.org/stream/govuscourtsca9briefs3369

Document Link: http://archive.org/stream/govuscourtsca9briefs3369#page/n870/mode/1up

Top Keywords (auto-generated):

baker, urban, 2d, work, costs, contract, cir, acceleration, 1960, finding, completion, extra, job, items, district

Top Key Phrases (auto-generated):

9th cir., completion dates, extra work, standard oil, prime contractor, construction schedule, sons inc., macri sons, increased costs, contract requirement, business tax, work performed, wing october, supra 313, originally contemplated

Document Status: UGLY