v2326-963

No. 10,229

IN THE

Winitth States;

Circuit Court of Appeals

jFor ttje ^intf) Citcuit v

AMERICAN SURETY COMPANY,

a Corporation,

Appellant,

vs.

UNITED STATES OF AMERICA,

Appellee.

APPEAL FROM THE UNITED STATES

DISTRICT COURT

for the District of Montana

BRIEF FOR THE APPELLEE

Honorable Charles N. Pray, District Judge

CT 1 1 r" n Francis M. Shea,

r I L- ' Assistant Attorney General,

lAM - 4 1943 J^^^ ^- Tansil,

jAi^ 4 i:7Ho C/mY^J States Attorney,

PAUL P. O eiMcN, R. Lewis Brown

CLE.RK

Assistant United States Attorney,

Leavenworth Colby,

Attorney, Department of Justice,

Attorneys for Appellee.

McKEE printins Co.. Butte. Mont.

---

archive.org Volume Name: govuscourtsca9briefs2326

Volume: http://archive.org/stream/govuscourtsca9briefs2326

Document Link: http://archive.org/stream/govuscourtsca9briefs2326#page/n962/mode/1up

Top Keywords (auto-generated):

contract, government, work, damages, contractor, delay, completion, liquidated, article, surety, right, district, officer, contracting, building

Top Key Phrases (auto-generated):

delay damages, contracting officer, liquidated delay, american surety, liquidated damages, completion contract, maryland casualty, dam ages, gov ernment, specified completion, standard form, grogan contract, government elects, completed building, continental casualty

Document Status: UGLY