v2824-557

Document Title Page

No. 13740

United States

COURT OF APPEALS

for the Ninth Circuit

NORTHEAST CLACKAMAS COUNTY ELECTRIC

CO-OPERATIVE, INC., a Corporation,

Appellant,

vs.

CONTINENTAL CASUALTY COMPANY, a Corpora-

tion, and S. H. RIPP, Doing Business as Ripp Electric

Company,

Appellee.

    1. RIPP, Doing Business as Ripp Electric Company,

Appellant,

vs.

NORTHEAST CLACKAMAS COUNTY ELECTRIC

CO-OPERATIVE, INC., a Corporation,

Appellee.

BRIEF FOR APPELLEE,

CONTINENTAL CASUALTY COMPANY

Appeals from the United States District Court for the

District of Oregon.

James L. Conley,

Conley & Greene,

805 Equitable Building,

Portland, Oregon,

Attorneys for Appellee, Continental Casualty Company.

STEVENS-NESS LAW PUB. CO.. PORTLAND 10-53


archive.org Volume Name: govuscourtsca9briefs2824

Volume: http://archive.org/stream/govuscourtsca9briefs2824

Document Link: http://archive.org/stream/govuscourtsca9briefs2824#page/n556/mode/1up

Top Keywords (auto-generated):

contract, op, contractor, work, construction, right, ripp, delay, extension, december, progress, owner, damages, clearing, supra

Top Key Phrases (auto-generated):

progress payments, continental casualty, construction work, rogers construction, guerini stone, bates rogers, storm damage, delay caused, clackamas county, quantum meruit, operative inc., december 1st, damage clause, county electric, wright kremers

Document Status: UGLY